Terms & Condistions for the Sale of Goods and Services

The Buyer’s attention is in particular drawn to the provisions of condition 13.

1. INTERPRETATION

1.1 The definitions and rules of interpretation in this condition apply in these
conditions.

Business Day: a day (other than a Saturday, Sunday or public holiday)
when banks in London are open for business.
Buyer: the firm or company who purchases the Goods from the Company.
Budgetary Proposals: informal non-binding estimates given to the Buyer
by the Company in respect of its Good and / or Services.
Collection: the collection of the Goods from the Company’s place of
business by the Buyer or its agent.
Company: G.B. Lighting Limited t/a Heathfield & Co (Company no:
01343559)
Conditions: the terms and conditions as set out in this agreement.
Contract: any contract between the Company and the Buyer for the sale
and purchase of the Goods, incorporating these Conditions.
Data Protection Legislation: the UK Data Protection Legislation and (for
so long as and to the extent that the law of the European union has legal
effect in the UK) the GDPR and any other directly applicable European
Union regulation relating to privacy.
Delivery: the delivery of the Goods by the Company to the Delivery Point
in accordance with condition 4.
Delivery Point: the place specified by the Buyer where Delivery or
Collection of the Goods is to take place under condition 4.
Force Majeure Event: has the meaning given in condition 15.
GDPR: General Data Protection Regulations ((EU) 2016/679).
Goods: any goods agreed in the Contract to be supplied to the Buyer by
the Company (including any part or parts of them).
Installation: the installation of the Goods by the Buyer or their contractors
at the location specified by the Buyer.
Intellectual Property Rights: patents, utility models, rights to inventions,
copyright and neighbouring and related rights, moral rights, trade
marks and service marks, business names and domain names, rights
in get-up and trade dress, goodwill and the right to sue for passing off
or unfair competition, rights in designs, rights in computer software,
database rights, rights to use, and protect the confidentiality of,
confidential information (including know-how and trade secrets), and
all other intellectual property rights, in each case whether registered or
unregistered and including all applications and rights to apply for and be
granted, renewals or extensions of, and rights to claim priority from, such
rights and all similar or equivalent rights or forms of protection which
subsist now or in the future in any part of the world.
Manufacture: the manufacture of the Goods by the Company for the
Buyer.
Order: the Buyer’s order for the supply of Goods and/or Services, as set
out the Buyer’s written acceptance of the Company’s quotation.
Services: any services agreed in the Contract to be supplied to the Buyer
by the Company (including any part or parts of them).
Specification: any Specification for the Goods, including any related plans
and drawings, that is agreed in writing by the Buyer and the Company.
UK Data Protection Legislation: any data protection legislation from
time to time in force in the UK including the Data Protection Act 1998 or
2018 or any successor legislation.

1.2 Words in the singular include the plural and in the plural include the
singular.

1.3 A reference to one gender includes a reference to the other gender.

1.4 Condition headings do not affect the interpretation of these conditions.

1.5 A reference to a particular law is a reference to it as it is in force for the
time being taking account of any amendment, extension, application or
re-enactment and includes any subordinate legislation for the time being
in force made under it.

1.6 A person includes a natural person, corporate or unincorporated body
(whether or not having separate legal personality).

1.7 A reference to a statute or statutory provision is a reference to it as
amended or re-enacted. A reference to a statute or statutory provision
includes all subordinate legislation made under that statute or statutory
provision.

1.8 Any words following the terms including, include, in particular, for
example or any similar expression shall be construed as illustrative and
shall not limit the sense of the words, description, definition, phrase or
term preceding those terms.

1.9 A reference to writing or written includes email but not fax.

1.10 A reference to a party includes its personal representatives, successors
and permitted assigns.

2. APPLICATION OF TERMS

2.1 The Contract shall be on these conditions to the exclusion of all other
terms and conditions that the Buyer seeks to impose or incorporate, or
which are implied by trade, custom, practice or course of dealing.

2.2 The Contract constitutes the entire agreement between the parties
and supersedes and extinguishes all previous agreements, promises,
assurances, warranties, representations and understandings between
them, whether written or oral, relating to its subject matter. The
Buyer acknowledges that it has not relied on any statement, promise,
representation, assurance or warranty made or given by or on behalf
of the Company which is not set out in the Contract. Each party agrees
that it shall have no claim for innocent or negligent misrepresentation
or negligent misrepresentation based on any statement in the Contract.
Nothing in this condition shall limit or exclude any liability for fraud.

2.3 Orders will not be accepted against Budgetary Proposals.

2.4 Each Order or acceptance of a formal quotation for Goods and/or
Services by the Buyer from the Company shall be deemed to be an offer
by the Buyer to buy Goods and/or Services subject to these Conditions.
The Buyer shall be responsible for ensuring that the terms of its Order are
complete and accurate.

2.5 No Order placed by the Buyer shall be deemed to be accepted by the
Company until a written acknowledgement of the order is issued by the
Company or (if earlier) the Company delivers the Goods to the Buyer, at
which point the Contract shall come into existence.

2.6 An accepted Order may only be cancelled or varied with the Company’s
written consent. In the event that the Buyer wishes to vary the Order,
including any agreed Specifications, delivery dates, Installation dates
or times, the Company reserves the right to charge the Buyer for the
Company’s additional costs (including, without limitation, any indirect,
special or consequential loss, loss of profit and other economic losses)
incurred in relation to the variation of the Order.

2.7 Any quotation is given on the basis that no Contract shall come into
existence until the Company dispatches an acknowledgement of Order
to the Buyer. Unless specifically stipulated in writing on the quotation,
any quotation is valid for a period of thirty (30) days only from its date,
provided that the Company has not previously withdrawn it.

3. DESCRIPTION

3.1 The quantity and description of the Goods shall be as set out in the
Specification attached to the quotation or acknowledgement of the
Order. The Buyer shall satisfy itself that the Specification is correct and
accurately describes its requirements. The Company reserves the right to
amend the Specification of the Goods if required by applicable statutory
or regulatory requirements. The Company reserves the right to make
minor amendments to the Specification as it deems necessary in order
to aid the manufacturing process. The Company shall notify the Buyer
in advance of making any amendments to the Specification that the
Company considers, in its reasonable opinion, to be of a material nature
or likely to affect the Buyer’s use of the Goods.

3.2 Whilst the Company takes every precaution in the preparation of its
catalogues, technical circulars, tear sheets, price lists and its other
literature these documents are for the Buyer’s general guidance only, for
giving an approximate idea of the Goods described in them, and shall not constitute representations by the Company and shall not form part of the Contract.

4. DELIVERY/COLLECTION

4.1 Dispatch of the Goods shall take place by the Company delivering them
to, or the Buyer or its agent collecting them from, the Delivery Point,
whichever is agreed between the parties in writing.

4.2 Delivery of the Goods to the Delivery Point shall be at the Buyer’s expense unless otherwise stated by the Company.

4.3 The Buyer shall provide at the Delivery Point at the time of Delivery or
Collection and at its expense, adequate and appropriate equipment
and manual labour for unloading or loading the Goods. In doing so, the
Buyer shall not cause any delay to the Company.

4.4 If the Company is delivering the Goods, any dates specified by the
Company for Delivery of the Goods are intended to be an estimate and
time for Delivery shall not be made of the essence. If no dates are so
specified, delivery shall be within a reasonable time.

4.5 If the Buyer is collecting the Goods, Collection must take place within
three (3) daysBusiness Days of the Company notifying the Buyer in writing
that the Goods are ready for collection. Time of Collection is of the
essence.

4.6 If for any reason the Buyer fails to accept Delivery of any of the Goods
when they are ready for Delivery, or fails to collect the Goods when they
are ready for Collection in accordance with the timescale in condition
4.5, or the Company is unable to deliver the Goods on time because
the Buyer has not provided appropriate instructions, documents, licences
authorisations or appropriate equipment and manual labour for unloading
the Goods:

4.6.1 risk in the Goods shall pass to the Buyer (including for loss or
damage caused by the Company’s negligence);

4.6.2 the Goods shall be deemed to have been delivered or collected;

4.6.3 the Company may store the Goods until Delivery or Collection
takes place, whereupon the Buyer shall be liable for all related
costs and expenses (including, without limitation, storage and
insurance); and

4.6.4 the payments due under the Contract shall not be delayed.

4.7 If ten (10) Business Days after the day on which the Buyer fails to accept
Delivery of the Goods, or fails to collect the Goods when they are ready
for Collection in accordance with the timescale in condition 4.5, the
Buyer has not accepted or taken the Goods, the Company may resell
or otherwise dispose of part or all of the Goods and after deducting
reasonable storage and selling costs, account to the Buyer for any excess
over the price of the Goods or charge the Buyer for any shortfall below
the price of the Goods.

4.8 The Company may deliver the Goods or the Buyer or its agent may, if
agreed with the Company, collect the Goods, by separate instalments
which shall be invoiced and paid for separately. Each instalment shall be
a separate Contract. Any delay in delivery or defect in an instalment shall
not entitle the Buyer to cancel any other instalment.

5. NON-DELIVERY

5.1 The quantity of any consignment of Goods as recorded by the Company
on dispatch from the Company’s place of business shall be conclusive
evidence of the quantity received by the Buyer on delivery unless the
Buyer can provide conclusive written evidence proving the contrary
within 24 (twenty four) hours of Delivery or Collection.

5.2 The Company shall not be liable for any non-delivery of Goods (even
if caused by the Company’s negligence) unless the Buyer gives written
notice to the Company of the non-delivery within five (5) days of the
date when the Goods would in the ordinary course of events have been
received.

5.3 Any liability of the Company for non-delivery of the Goods shall be limited
to replacing the Goods within a reasonable time. The Company shall
have no liability for any failure to deliver the Goods to the extent that
such failure is caused by a Force Majeure Event or the Buyer’s failure to
provide the Company with adequate delivery instructions or any other
instructions that are relevant to the supply of the Goods.

6. RISK/TITLE

6.1 The Goods are at the risk of the Buyer from the time of Delivery or
Collection, subject to condition 4.6.

6.2 Title to the Goods shall not pass to the Buyer until the Company has
received in full (cleared funds) all sums due to it in respect of:

6.2.1 the Goods;

6.2.2 the Services; and

6.2.3 all other sums which are or which become due to the Company
from the Buyer on any account.

6.3 The Buyer may resell the Goods before title has passed to it solely on the following conditions:

6.3.1 any sale shall be effected in the ordinary course of the Buyer’s
business at full market value and the Buyer shall hold such part
of the proceeds of sale as represents the amount owed by the
Buyer to the Company on behalf of the Company and the Buyer
shall account to the Company accordingly; and

6.3.2 any such sale shall be a sale of the Company’s property on the
Buyer’s own behalf and the Buyer shall deal as principal when
making such a sale.

6.3.3 title to the Goods shall pass from the Company to the Buyer
immediately before the time at which resale by the Buyer
occurs.

6.4 Until title to the Goods has passed to the Buyer, the Buyer shall:

6.4.1 hold the Goods on a fiduciary basis as the Company’s bailee;

6.4.2 store the Goods (at no cost to the Company) separately from all
other goods of the Buyer or any third party in such a way that
they remain readily identifiable as the Company’s property;

6.4.3 not remove, destroy, deface or obscure any identifying mark or
packaging on or relating to the Goods;

6.4.4 maintain the Goods in satisfactory condition and keep them
insured on the Company’s behalf for their full price against all
risks to the reasonable satisfaction of the Company. On request
the Buyer shall produce the policy of insurance to the Company;

6.4.5 give the Company such information relating to the Goods as
the Company may require from time to time, but the Buyer may
resell or use the Goods in accordance with condition 6.3; and

6.4.6 notify the Company immediately if it becomes subject to any of
the events listed in condition 12.2.

6.5 The Buyer’s right to possession of the Goods shall terminate immediately if, before title to the Goods passes to the Buyer:

6.5.1 the Buyer becomes subject to any of the events listed in
condition 12.2; or

6.5.2 the Buyer suffers or allows any execution, whether legal or
equitable, to be levied on his/its property or obtained against
him/it, or fails to observe or perform any of his/its obligations
under the Contract or any other contract between the Company
and the Buyer; or

6.5.3 the Buyer encumbers or in any way charges any of the Goods.

6.6 The Company shall be entitled to recover payment for the Goods
notwithstanding that title to any of the Goods
has not passed from the Company.

6.7 The Buyer grants the Company, its agents and employees an
irrevocable licence at any time to enter any premises where the Goods
are or may be stored in order to inspect them, or, where the Buyer’s right
to possession has terminated, to recover them (provided that the Goods
have not been resold or irrevocably incorporated into another product).

6.8 Where the Company is unable to determine whether any Goods are the
goods in respect of which the Buyer’s right to possession has terminated,
the Buyer shall be deemed to have sold all Goods of the kind sold by
the Company to the Buyer in the order in which they were invoiced to
the Buyer.

6.9 The risk in any Goods sold for export outside the UK passes to the Buyer
upon receipt of the Goods by the Buyer or his shipping agent and the
Buyer shall indemnify the Company against any consequences of any
breach of foreign laws, regulations or licensing requirements in relation
to the Goods supplied.

6.10 On termination of the Contract, howsoever caused, the Company’s (but not the Buyer’s) rights contained in this condition 6 shall remain in effect.

7. SUPPLY OF SERVICES

7.1 The Company shall supply the Services to the Buyer in accordance with
the Order in all material respects.

7.2 The Company shall use all reasonable endeavours to meet any
performance dates for the Services specified in the Order or as notified
by the Company to the Buyer, but any such dates shall be estimates only
and time shall not be of the essence for the performance of the Services.

7.3 The Company reserves the right to amend the Order if necessary to
comply with any applicable law or regulatory requirement, or if the
amendment will not materially affect the nature or quality of the Services,
and the Company shall notify the Buyer in any such event.

7.4 The Company warrants to the Buyer that the Services will be provided
using reasonable care and skill.

8. BUYER’S OBLIGATIONS

8.1 The Buyer shall:

8.1.1 ensure that the terms of the Order are complete and accurate;

8.1.2 co-operate with the Company in all matters relating to the
Services;

8.1.3 provide the Company, its employees, agents, consultants and
subcontractors, with access to the Buyer’s premises and other
facilities as reasonably required by the Company to provide the
Services;

8.1.4 provide the Company with such information and materials as
the Company may reasonably require in order to supply the
Services, and ensure that such information is complete and
accurate in all material respects;

8.1.5 obtain and maintain all necessary licences, permissions, and
consents which may be required for the Services before the
date on which the Services are to start;

8.1.6 comply with all applicable laws, including health and safety
laws;

8.1.7 keep all materials, equipment, documents and other property
of the Company (Company Materials) at the Buyer’s premises in
safe custody at its own risk, maintain the Company Materials in
good condition until returned to the Company or paid for by the
Buyer, and not dispose of or use the Company Materials other
than in accordance with the Company’s written instructions or
authorisations;

8.1.8 comply with any additional obligations as set out in the Order;
and

8.1.9 carry out any applicable health and safety assessments in
relation to the Goods prior to installing and using them.

8.2 If the Company’s performance of any of its obligations under the Contract
is prevented or delayed by any act or omission by the Buyer or failure by
the Buyer to perform any relevant obligations (Buyer Default):

8.2.1 without limiting or affecting any other right or remedy available
to it, the Company shall have the right to suspend performance
of the Services until the Buyer remedies the Buyer Default, and
to rely on the Buyer Default to relieve it from the performance
of any of its obligations in each case to the extent the Buyer
Default prevents or delays the Company’s performance of any
of its obligations;

8.2.2 the Company shall not be liable for any costs or losses sustained
or incurred by the Buyer arising directly or indirectly from the
Company’s failure or delay to perform any of its obligations as
set out in this condition 8.2; and

8.2.3 the Buyer shall reimburse the Company on written demand
for any costs or losses sustained or incurred by the Company
arising directly or indirectly from the Buyer Default.

9. PRICE

9.1 Subject to condition 2.3 and condition 2.6, the price for the Goods and/
or Services shall be the price set out in the quotation. If no quotation is
given, or a quotation is no longer valid:
9.1.1 the price for the Goods shall be the price set out in the
Company’s price list published on the date of Delivery or
Collection or deemed delivery or collection.

9.1.2 the price for the Services shall be calculated in accordance with
the Company’s standard daily rate, with any part-day charged
at the cost of a full day as set out in its current price list at the
date of the Contract or as otherwise stated by the Company.
The Company shall be entitled to charge the Buyer for any
expenses reasonably incurred by the individuals whom the
Company engages in connection with the Services.

9.2 The Company may, by giving notice to the Buyer at any time before
delivery, increase the price of the Goods and/or Services to reflect any
increase in the cost of the Goods and/or Services that is due to:

9.2.1 any factor beyond the Company’s control (including foreign
exchange fluctuations, increases in taxes and duties, and
increases in labour, materials and other manufacturing costs);

9.2.2 any request by the Buyer to change the Specification, delivery
dates, quantities or types of Goods ordered;

9.2.3 any delay caused by any instructions of the Buyer or failure
of the Buyer to give the Company adequate or accurate
information or instructions; and

9.2.4 any failure of the Buyer to comply with any other provision of
these conditions for which it is responsible.

9.3 Unless otherwise stated on the quotation, the price for the Goods
excludes:

9.3.1 amounts in respect of value added tax (VAT), unless otherwise
stated, which where applicable the Buyer shall additionally be
liable to pay to the Company at the prevailing rate, subject to
the receipt of a valid VAT invoice;

9.3.2 the costs and charges or packaging, insurance and transport of
the Goods, which shall be invoiced to the Buyer;

9.3.3 any import or export duties, taxes, duties or charges which shall
be the responsibility of the Buyer to pay;

9.3.4 the cost of any customs certificates (such as, but not limited
to, SASO, EUR.1 or ATR1 Certificates) any costs associated with
which shall be payable by the Buyer; and

9.3.5 the cost of any certification of the Goods outside of the
European Union (including, but not limited to, UL Listing and
UL

9.4 The Company shall not be obliged to dispatch the Goods until the full
price (including any taxes, charges or costs referred to in condition 9.2
above) has been paid in cleared funds, and may, in its sole discretion,
cancel or delay delivery of the Goods until it has received such payment.

9.5 UK VAT will be charged on all Orders for Goods and/ or Services unless
the Buyer supplies evidence to the Company’s satisfaction that:

9.5.1 The supply is zero-rated or exempt; or

9.5.2 The Buyer is VAT registered in the European Union and that
the relevant export requirements imposed by HMRC at the time
have been met; or

9.5.3 The Buyer uses an approved shipping agent for export
abroad and the Company receives a satisfactory Certificate of
Shipment.

9.6 If any import duties, tariffs or levy are imposed upon the sale, licensing or other transfer of the Goods from the United Kingdom to a member state
of the European Union those charges shall be paid by Buyers.

9.7 The Buyer is responsible for obtaining, at its own cost, such import
licences and other consents in relation to the Goods as are required
from time to time and, if required by the Company, the Buyer shall make
those licences and consents available to the Company prior to the
relevant shipment.

10. PAYMENT

10.1 The Company shall invoice and require payment for the full value of the
Goods and/or Services in advance of Manufacture. The Company may,
at its sole and absolute discretion, agree alternative payment terms with
the Buyer, including credit terms.

10.2 Where Manufacture, Delivery or Collection is by instalments, the Buyer
may be invoiced for each separate instalment on or at any time after the
completion of each instalment.

10.3 Depending on the nature of the Goods and the duration of the Contract, the Company reserves the right to require a deposit with the Order andthe Buyer may be sent an invoice on receipt of the Order and on each agreed stage.

10.4 Where credit terms have been agreed, and subject to condition 8.8,
the Buyer shall pay each invoice submitted to it by the Company within
thirty (30) days of receipt of the invoice. Time for payment shall be of the
essence.

10.5 The Company will accept payments made by bank transfer (BACS) as the preferred payment method. Debit/credit card payments (excluding American Express) will be accepted up to a maximum order value of £5k.  Any orders exceeding £5k (or the equivalent in an alternative currency) will need to be paid via bank transfer.

10.6 No payment shall be deemed to have been received until the Company has received full and cleared funds. A Delivery or Collection date cannot be confirmed until the clearance of funds. The Company will not accept liability for bank charges.

10.7 All payments shall be made in the currency specified on the invoice. If
payment is made in any other currency, or attracts any other charges in
transfer to the Company’s bank account, the Buyer will meet all charges and costs incurred by the Company in exchanging or cashing such payments.

10.8 All payments payable to the Company under the Contract shall become due immediately on its termination despite any other provision.
10.9 The Buyer shall make all payments due under the Contract in full
without any deduction whether by way of set-off, counterclaim, discount,
abatement or otherwise unless the Buyer has a valid court order requiring
an amount equal to such deduction to be paid by the Company to the
Buyer.

10.10 If the Buyer fails to pay the Company any sum due pursuant to the
Contract, the Buyer shall be liable to pay interest to the Company on such
sum from the due date for payment at the annual rate of 4% above the
base lending rate from time to time of HSBC Bank plc, accruing on a daily
basis until payment is made, whether before or after any judgment. The
Buyer shall pay the interest together with the overdue amount.

10.11 Where payment is to be by instalments the Company shall not be bound to take any step in performance of the Contract until the Buyer has paid the deposit or first instalment and if the Buyer shall fail promptly to pay the second or any subsequent instalment the Company shall be entitled to suspend or terminate its performance of the Contract and to call on the Buyer to furnish a bank guarantee for the due payment of the
outstanding balance of the price.

11. QUALITY

11.1 The Company warrants that (subject to the other provisions of these
conditions) on Delivery or Collection, and for twelve (12) months from
the date of Delivery or Collection, the Goods shall be of satisfactory
quality (with the meaning of the Sale of Goods Act 1978) and free from
manufacturing defects in design, material and workmanship.

11.2 Subject to condition 11.3, the Company shall not be liable for a breach of
the warranty in condition 11.1 unless:

11.2.1 the Buyer gives written notice of the defect to the Company,
and, if the defect is as a result of damage in transit to the
carrier, within three (3) Business Days of Delivery; and

11.2.2 the Company is given a reasonable opportunity after receiving
the notice of examining such Goods and the Buyer (if asked to
do so by the Company) returns such Goods to the Company’s
place of business at the Company’s cost for the examination to
take place there.

11.3 The Company shall not be liable for a breach of the warranty in condition

11.1 if:

11.3.1 the Buyer makes any further use of such Goods after giving such
notice in accordance with condition 11.2.2; or

11.3.2 the defect arises because the Buyer failed to follow the
Company’s oral or written instructions as to the storage,
installation, commissioning, use or maintenance of the Goods
or (if there are none) good trade practice;

11.3.3 the defect arises as a result of fair wear and tear, wilful damage,
negligence or abnormal storage or working conditions;

11.3.4 the Buyer alters or repairs such Goods without the written
consent of the Company;

11.3.5 he Goods differ from their description as a result of changes
made to ensure they comply with applicable statutory or
regulatory standards or other necessary amendment pursuant
to condition 3.1.

11.4 Subject to condition 11.2 and condition 11.3, if any of the Goods do not
conform with the warranty in condition 11.1 the Company shall at its
option repair or replace such Goods (or the defective part) or refund the
price of such Goods at the pro rata Contract rate provided that, if the
Company so requests, the Buyer shall, at the Buyer’s expense, return the
Goods or the part of such Goods which is defective to the Company.

11.5 If the Company complies with condition 11.4 it shall have no further
liability whatsoever for a breach of the warranty in condition 11.1 in
respect of such Goods.

11.6 These conditions shall apply to any repaired or replacement Goods
supplied by the Company.

12. TERMINATION

12.1 If the Buyer becomes subject to any of the events listed in condition

12.2, or the Company reasonably believes that the Buyer is about to
become subject to any of them and notifies the Buyer accordingly, then,
without limiting any other right or remedy available to the Company,
the Company may cancel or suspend by giving written notice all further
deliveries under the Contract or under any other contract between the
Buyer and the Company without incurring any liability to the Buyer, and
all outstanding sums in respect of Goods and/or Services delivered to the
Buyer shall become immediately due.

12.2 For the purposes of condition 12.1, the relevant events are:

12.2.1 the Buyer fails to pay any amount due under the Contract on
the due date for payment;

12.2.2 the Buyer suspends, or threatens to suspend, payment of its
debts, or is unable to pay its debts as they fall due or admits
inability to pay its debts, or (being a company or limited
liability partnership) is deemed unable to pay its debts within
the meaning of section 123 of the Insolvency Act 1986, or
(being an individual) is deemed either unable to pay its debts
or as having no reasonable prospect of so doing, in either
case, within the meaning of section 268 of the Insolvency Act
1986, or (being a partnership) has any partner to whom any of
the foregoing apply;

12.2.3 the Buyer commences negotiations with all or any class of its
creditors with a view to rescheduling any of its debts, or makes
a proposal for or enters into any compromise or arrangement
with its creditors other than where the Buyer is a company)
where these events take place for the sole purpose of a
scheme for a solvent amalgamation of the Buyer with one or
more other companies or the solvent reconstruction of the
Buyer;

12.2.4 (being a company) a petition is filed, a notice is given, a
resolution is passed, or an order is made, for or in connection
with the winding up of the Buyer, other than for the sole
purpose of a scheme for a solvent amalgamation of the
Buyer with one or more other companies or the solvent
reconstruction of the Buyer;

12.2.5 (being an individual) the Buyer is the subject of a bankruptcy
petition or order;

12.2.6 a creditor or encumbrancer of the Buyer attaches or takes
possession of, or a distress, execution, sequestration or other
such process is levied or enforced on or sued against, the
whole or any part of its assets and such attachment or process
is not discharged within 5 (five) days;

12.2.7 (being a company) an application is made to court, or an
order is made, for the appointment of an administrator or if a
notice of intention to appoint an administrator is given or if an
administrator is appointed over the Buyer;

12.2.8 (being a company) the holder of a qualifying charge over
the Buyer’s assets has become entitled to appoint or has
appointed an administrative receiver;

12.2.9 a person becomes entitled to appoint a receiver over the
Buyer’s assets or a receiver is appointed over the Buyer’s
assets;

12.2.10 any event occurs, or proceeding is taken, with respect to the
Buyer in any jurisdiction to which it is subject that has an
effect equivalent or similar to any of the events mentioned in
condition 12.2.2 to condition 12.2.9 (inclusive);

12.2.11 the Buyer suspends, threatens to suspends, ceases or threatens
to cease to carry on all or a substantial part of its business;

12.2.12 the Buyer’s financial position deteriorates to such an extent
that in the Company’s opinion the Buyer’s capability to
adequately fulfil its obligations under the Contract has been
placed in jeopardy; and

12.2.13 (being an individual) the Buyer dies or, by reason of illness
or incapacity (whether mental or physical), is incapable of
managing his or her own affairs or becomes a patient under
any mental health legislation.

12.3 Termination of the Contract, however arising, shall not affect any of
the parties’ rights and remedies that have accrued as at termination.
Conditions which expressly or by implication survive termination of the
Contract shall continue in full force and effect.

12.4 On termination of the Contract:

12.4.1 the Buyer shall immediately pay to the Company all of the
Company’s outstanding unpaid invoices and interest and,
in respect of Services and / or Goods supplied but for which
no invoice has been submitted, the Company shall submit an
invoice, which shall be payable by the Buyer immediately on
receipt; and

12.4.2 the Buyer shall return all of the Company Materials and any Goods which have not been fully paid for. If the Buyer fails to do
so, then the Company may enter the Buyer’s premises and take
possession of them. Until they have been returned, the Buyer
shall be solely responsible for their safe keeping and will not
use them for any purpose not connected with this Contract.

13. LIMITATION OF LIABILITY

13.1 Subject to condition 4, condition 5 and condition 11, the following
provisions set out the entire financial liability of the Company (including
any liability for the acts or omissions of its employees, agents and subcontractors)
to the Buyer in respect of:

13.1.1 any breach of these conditions;

13.1.2 any use made or resale by the Buyer of any of the Goods, or of
any product incorporating any of the Goods; and

13.2 All warranties, conditions and other terms implied by statute or common
law are, to the fullest extent permitted by law, excluded from the Contract.

13.3 Nothing in these conditions excludes or limits the liability of the Company:

13.3.1 for death or personal injury caused by the Company’s
negligence, or the negligence of its employees, agents or subcontractors
(as applicable); or

13.3.2 under section 2(3), Consumer Protection Act 1987; or

13.3.3 for any matter which it would be illegal for the Company to
exclude or attempt to exclude its liability; or

13.3.4 for fraud or fraudulent misrepresentation.

13.4 Subject to condition 13.2 and condition 13.3:

13.4.1 the Company’s total liability in contract, tort (including
negligence or breach of statutory duty), misrepresentation,
restitution or otherwise, arising in connection with the
performance or contemplated performance of the Contract
shall not exceed 100% of the price of the Goods and/or Services
as set out in the Order; and

13.4.2 the following types of loss are wholly excluded:
(a) Loss of profits.
(b) Loss of sales or business.
(c) Loss of agreements or contracts.
(d) Loss of anticipated savings.
(e) Loss of use or corruption of software, data
information.
(f) Loss of damage to goodwill.
(g) Indirect or consequential loss.
(h) Costs of, or relating to, the Installation or reinstallation
of the Goods, other than those costs
which are reasonable and properly incurred as
direct result of defective Goods or assembly.

13.5 Unless the Buyer notifies the Company that it intends to make a claim in
respect of an event within the notice period, the Company shall have no
liability for that event. The notice period for an event shall start on the
day on which the Buyer became, or ought reasonably to have become,
aware of its having grounds to make a claim in respect of the event and
shall expire one month from that date. The notice must be in writing
and must identify the event and the grounds for the claim in reasonable
detail.

13.6 This condition 13 shall survive termination of the Contract.

14. ASSIGNMENT/SUB-LETTING

14.1 The Company may assign or sub-contract the Contract or any part of it
to any person, firm or company.

14.2 The Buyer shall not be entitled to assign the Contract or any part of it
without the prior written consent of the Company.

15. FORCE MAJEURE

The Company reserves the right to defer the date of Delivery or Collection
or to cancel the Contract or reduce the volume of the Goods and/
or Services ordered by the Buyer (without liability to the Buyer) if it is
prevented from or delayed in the carrying on of its business due to a
Force Majeure Event. A Force Majeure Event means any event beyond the
reasonable control of the Company including, without limitation, acts of
God, governmental actions, war or national emergency, acts of terrorism,
protests, riot, civil commotion, fire, explosion, flood, epidemic, lock-outs,
strikes or other labour disputes (whether or not relating to either party’s
workforce), or restraints or delays affecting carriers or inability or delay in
obtaining supplies of adequate or suitable materials, provided that, if the
event in question continues for a continuous period in excess of ninety
(90) Business Days, the Buyer shall be entitled to give notice in writing to
the Company to terminate the Contract by giving ten (10) Business Days
written notice to the Company.

16. ON SITE ASSEMBLY

16.1 If the Company undertakes to assemble the Goods or assist the Buyer or
their contractor (where required) in installing the Goods at the Buyer’s
premises the following additional terms shall apply:

16.1.1 the Company shall be given clear, safe and unobstructed access
to the premises and applicable immediate surrounding area(s);

16.1.2 the Company shall be entitled to use free of charge such
supplies of electricity, water, gas and other services as may be
reasonably required to carry out the services provided;

16.1.3 the Buyer shall provide at its own expense such temporary
roadways, footways, scaffolding, lifting, equipment and the like
as may be reasonably required for the safe completion of the
Installation;

16.1.4 the Buyer shall at its own expense be responsible for the
cleaning out and preparation of the site prior to Installation;

16.1.5 the Buyer shall at its own expense be responsible for the
proper fencing, guarding, lighting and protection of the works
during the Installation and until it is completed;

16.1.6 the Buyer shall give the Company facilities for carrying out the
works on the site continuously during the normally recognised
working hours or at such other hours as the Company shall in
its sole discretion specify;

16.1.7 the Buyer shall provide secure and suitable on-site facilities
for the storage of Goods and/or Company Materials until their
Installation;

16.1.8 the Buyer is responsible for the connection of the Goods to
the electrical supply in accordance with all applicable laws and
regulations;

16.1.9 the Buyer shall carry out any health and safety or risk
assessments in relation to the Goods and Installation in
accordance with any applicable laws and regulations; and

16.1.10 the Buyer shall satisfy itself that the Installation has been
completed to a satisfactory standard immediately following
Installation and in any event prior to using the Goods.

16.2 Notwithstanding any assistance the Company may provide during the
Installation, the Company accepts no liability for the Installation of the
Goods by the Buyer, their contractors, or any other third parties and any
such liability is excluded to the fullest extent permissible.

17. INDEMNITY

17.1 The Buyer shall keep the Company fully and effectively indemnified
against:

17.1.1 any claims for infringement of any patent, registered design
or trade mark or any other rights of a third party by reason of
the Buyer’s requirements for the provision of any modified or
specifically designed Goods, to the Buyer’s design and at the
Buyer’s request, and against all costs and damages which the
Company may incur in any action for such infringement; and

17.1.2 any claim in contract or tort or otherwise to pay direct or
indirect damages expenses or costs relating to damage
to property or injury or loss to any person, firm or company
occasioned by reason of any act or omission by the Buyer or
any employee, agent or sub-contractor of it.

18. INTELLECTUAL PROPERTY

18.1 All Intellectual Property Rights arising in or arising out of or in connection with the Goods and / or Services shall remain the exclusive property of the Company and shall not be used, distributed, licensed, disclosed or registered by the Buyer or any third party without prior written consent of the Company.

18.2 All Goods (including codes and names), registered designs, drawings,
images, photographs and descriptions may not be reproduced
whatsoever without the prior written consent of the Company.

18.3 The Buyer acknowledges that many of the Goods supplied are the subject of patents, patent applications and/or registered designs in the United Kingdom and other countries.

19. DATA PROTECTION

19.1 Both parties will comply with all applicable requirements of the Data
Protection Legislation. This condition in addition to, and does not relieve,
remove or replace, a party’s obligations under the Data Protection
Legislation.

19.2 To the extent that the Company, now or at any stage in the future,
processes any personal data on behalf of the Buyer, the Company shall:

19.2.1 process such personal data only in accordance with the Buyer’s
instructions;

19.2.2 implement appropriate technical and organizational measures
to protect such personal data against unauthorized or unlawful
processing and against accidental loss, destruction, damage,
alteration or disclosure;

19.2.3 use reasonable endeavours to ensure the reliability of its
personnel with access to such personal data;

19.2.4 notify the Buyer, of any suspected, potential or actual
data incident, including any suspected, potential or actual
accidental, unlawful or unauthorized destruction, disclosure,
loss, alteration or access in relation to personal data processed
on behalf of the Buyer;

19.2.5 not subcontract any processing of such personal data without
the Buyer’s prior written consent; and

19.2.6 not process and/or transfer any such personal data to any
country outside the European Economic Area without the
Buyer’s prior written consent

20. CONFIDENTIALITY

20.1 The Buyer (or any receiving party) shall keep in strict confidence all
technical or commercial know-how, Specifications, inventions, processes
or initiatives which are of a confidential nature and have been disclosed
to the Buyer by the Company, its employees, agents or subcontractors,
and any other confidential information concerning the disclosing the
Company’s business, its Goods and Services which the Buyer may obtain.
The Buyer shall only disclose such confidential information to those of
its employees, agents and subcontractors who need to know it for the
purpose of discharging the Buyers obligations under the Contract, and
shall ensure that such employees, agents and subcontractors comply
with the obligations set out in this condition as though they were a
party to the Contract. The Buyer may also disclose such of the disclosing
party’s confidential information as is required to be disclosed by law,
any governmental or regulatory authority or by a court of competent
jurisdiction. This condition shall survive termination of the Contract.

20.2 Neither party shall use the other party’s confidential information for any purpose other than to perform its obligations under the Contract.

21. GENERAL

21.1 Each right or remedy of the Company under the Contract is without
prejudice to any other right or remedy of the Company whether under
the Contract or not.

21.2 If any provision or part-provision of the Contract is or becomes illegal,
invalid or unenforceable it shall be deemed modified to the minimum
extent necessary to make it legal, valid, and enforceable. If such
modification is not possible, the relevant provision or part-provision
shall be deemed deleted. Any modification or deletion of a provision
or part-provision under this condition shall not affect the validity and
enforceability of the rest of the Contract.

21.3 Failure or delay by the Company in enforcing or partially enforcing any
provision of the Contract shall not be construed as a waiver of any of its
rights under the Contract.

21.4 Any waiver by the Company of any breach of, or any default under, any
provision of the Contract by the Buyer shall not be deemed a waiver of
any subsequent breach or default and shall in no way affect the other
terms of the Contract.

21.5 In the event of a dispute between the parties arising out of the Contract, the parties shall negotiate in good faith. If unsuccessful, any dispute shall be referred to a single arbitrator who will be agreed between the parties or who failing such agreement shall be appointed at the request of the either party by the President of the Law Society.

21.6 The parties to the Contract do not intend that any term of the Contract
shall be enforceable by virtue of the Contracts (Rights of Third Parties) Act
1999 by any person that is not a party to it.

21.7 Except as set out in these Conditions, no variation to the Contract,
including the introduction of any additional terms and conditions, shall
be effective unless it is in writing and signed by the Company.

21.8 The Contract and any dispute or claim in connection with it or its subject matter (including non-contractual disputes or claims) shall be governed by English law and the parties submit to the exclusive jurisdiction of the English courts to settle any dispute or claim (including non-contractual disputes or claims) arising out of or in connection with the Contract or its subject matter or formation.

22. COMMUNICATIONS

22.1 All communications between the parties about the Contract shall be in
writing (which shall include email) and delivered by hand or sent by prepaid first class post or email:

22.1.1 in case of communications to the Company if:
(a) by post to its registered office or such changed
address as shall be notified to the Buyer by the
Company in writing; or
(b) by email to the email address of the person as shall
be notified to the Buyer by the Company in writing
from time to time; or

22.1.2 in the case of the communications to the Buyer if:
(a) by post to the registered office of the addressee (if it
is a company) or (in any other case) to any address
of the Buyer set out in any document which forms
part of the Contract or such other address as shall
be notified to the Company by the Buyer from time
to time or
(b) by email to any email address set out in any
document which forms part of the Contract or such
other email address as shall be notified to the
Company by the Buyer from time to time .

22.2 Communications shall be deemed to have been received if:
(a) sent by pre-paid first class post, two Business Days
after posting (exclusive of the day of posting); or
(b) delivered by hand, on the day of delivery; or
(c) sent by email on a working day prior to 4:00pm,
at the time of sending and otherwise on the next
Business Day.
22.3 Communications addressed to the Company shall be marked for the
attention of Edward Salter.
22.4 This condition does not apply to the service of any proceedings or other
documents in any legal action or, where applicable, any arbitration or
other method of dispute resolution.

DOWNLOAD PDF VERSION